Author: Institution of Civil Engineers (Great Britain)
Publisher: Thomas Telford
ISBN: 9780727720375
Category : Civil engineering
Languages : en
Pages : 44
Book Description
This edition of the ICE conditions of contract for minor works has been updated to include the following changes: a new clause on design responsibility; a paragraph on liquidated damages, identifying when damages may not be payable; many of the clauses have been deleted and replaced by updated versions consistent with the text of the ICE Conditions of Contract 6th edition; a clause to cover application to Northern Ireland; the recommended limit on contract value has been increased to u250,000 in place of the previous limit of u100,000; the recommended minimum cover for Third Party Insurance has been increased to u2 million; clauses are included on value added tax, and the requirements of the Construction, Design and Management Regulations 1994; and a set of guidance notes to help the reader to understand and implement the contract."
ICE Conditions of Contract for Minor Works
Author: Institution of Civil Engineers (Great Britain)
Publisher: Thomas Telford
ISBN: 9780727720375
Category : Civil engineering
Languages : en
Pages : 44
Book Description
This edition of the ICE conditions of contract for minor works has been updated to include the following changes: a new clause on design responsibility; a paragraph on liquidated damages, identifying when damages may not be payable; many of the clauses have been deleted and replaced by updated versions consistent with the text of the ICE Conditions of Contract 6th edition; a clause to cover application to Northern Ireland; the recommended limit on contract value has been increased to u250,000 in place of the previous limit of u100,000; the recommended minimum cover for Third Party Insurance has been increased to u2 million; clauses are included on value added tax, and the requirements of the Construction, Design and Management Regulations 1994; and a set of guidance notes to help the reader to understand and implement the contract."
Publisher: Thomas Telford
ISBN: 9780727720375
Category : Civil engineering
Languages : en
Pages : 44
Book Description
This edition of the ICE conditions of contract for minor works has been updated to include the following changes: a new clause on design responsibility; a paragraph on liquidated damages, identifying when damages may not be payable; many of the clauses have been deleted and replaced by updated versions consistent with the text of the ICE Conditions of Contract 6th edition; a clause to cover application to Northern Ireland; the recommended limit on contract value has been increased to u250,000 in place of the previous limit of u100,000; the recommended minimum cover for Third Party Insurance has been increased to u2 million; clauses are included on value added tax, and the requirements of the Construction, Design and Management Regulations 1994; and a set of guidance notes to help the reader to understand and implement the contract."
ICE Conditions of Contract for Minor Works
Author: Institution of Civil Engineers (Great Britain)
Publisher: Thomas Telford
ISBN: 0727729403
Category : Civil engineering contracts
Languages : en
Pages : 40
Book Description
The new edition of ICE Conditions of Contract for Minor Works has been updated to include relevant legislation such as the Housing Grants Construction and Regeneration (HGCR) Act, the Contracts (Right of Third Parties) Act, the Arbitration Act and a new national agreement the Scottish Arbitration Code with the ICE's annex (2001) to that code. Clause 11 has been modified so that the new addendum A is incorporated to accommodate both the HGCR and Arbitration Acts. notes show how the original disputes procedure replaces clause 11 and addendum A.
Publisher: Thomas Telford
ISBN: 0727729403
Category : Civil engineering contracts
Languages : en
Pages : 40
Book Description
The new edition of ICE Conditions of Contract for Minor Works has been updated to include relevant legislation such as the Housing Grants Construction and Regeneration (HGCR) Act, the Contracts (Right of Third Parties) Act, the Arbitration Act and a new national agreement the Scottish Arbitration Code with the ICE's annex (2001) to that code. Clause 11 has been modified so that the new addendum A is incorporated to accommodate both the HGCR and Arbitration Acts. notes show how the original disputes procedure replaces clause 11 and addendum A.
The ICE Conditions of Contract for Minor Works 1988
Author: Vincent Powell-Smith
Publisher:
ISBN:
Category :
Languages : en
Pages :
Book Description
Publisher:
ISBN:
Category :
Languages : en
Pages :
Book Description
Conditions of Contract, Agreement and Contract Schedule for Use in Connection with Minor Works of Civil Engineering Construction
Author: Institution of Civil Engineers (Great Britain)
Publisher: Thomas Telford
ISBN: 9780727713292
Category : Civil engineering
Languages : en
Pages : 32
Book Description
- Index - Agreement - The Contract Schedule - Definitions - Engineer - General obligations - Starting and completion - Defects - Additional payment - Payment - Assignment and sub-letting - Statutory obligations - Liabilities and insurance - Disputes - Scotland - Appendix to the Conditions of Contract
Publisher: Thomas Telford
ISBN: 9780727713292
Category : Civil engineering
Languages : en
Pages : 32
Book Description
- Index - Agreement - The Contract Schedule - Definitions - Engineer - General obligations - Starting and completion - Defects - Additional payment - Payment - Assignment and sub-letting - Statutory obligations - Liabilities and insurance - Disputes - Scotland - Appendix to the Conditions of Contract
ICE Conditions of Contract for Minor Works 1st edition
Author:
Publisher: Thomas Telford
ISBN: 9780727713292
Category : Civil engineering
Languages : en
Pages : 0
Book Description
Publisher: Thomas Telford
ISBN: 9780727713292
Category : Civil engineering
Languages : en
Pages : 0
Book Description
The ICE Conditions of Contract
Author: Brian Eggleston
Publisher: John Wiley & Sons
ISBN: 0470680083
Category : Technology & Engineering
Languages : en
Pages : 434
Book Description
The ICE Conditions continues to be the dominant form of contract for civil engineering, despite the growing importance of the New Engineering Contract. The Seventh Edition of the ICE Conditions, published in 1999, introduced a number of changes, including: incorporating some of the concepts of the Latham Report amending certain provisions of the Sixth Edition which had attracted criticism rectifying conspicuous omissions from the text of earlier editions of the contract correcting small errors and faults from the previous edition modernising certain provisions and terms Brian Eggleston, whose previous book on the ICE Conditions was described as 'likely to become the authoritative reference source for the Sixth Edition', examines the contract clause by clause from a practical and legal viewpoint. There is extensive coverage of case law. Written by an experienced civil engineer and recognized authority on construction contracts, this book is an essential guide.
Publisher: John Wiley & Sons
ISBN: 0470680083
Category : Technology & Engineering
Languages : en
Pages : 434
Book Description
The ICE Conditions continues to be the dominant form of contract for civil engineering, despite the growing importance of the New Engineering Contract. The Seventh Edition of the ICE Conditions, published in 1999, introduced a number of changes, including: incorporating some of the concepts of the Latham Report amending certain provisions of the Sixth Edition which had attracted criticism rectifying conspicuous omissions from the text of earlier editions of the contract correcting small errors and faults from the previous edition modernising certain provisions and terms Brian Eggleston, whose previous book on the ICE Conditions was described as 'likely to become the authoritative reference source for the Sixth Edition', examines the contract clause by clause from a practical and legal viewpoint. There is extensive coverage of case law. Written by an experienced civil engineer and recognized authority on construction contracts, this book is an essential guide.
ICE Conditions of Contract
Author: Institution of Civil Engineers
Publisher: Thomas Telford
ISBN: 0727727893
Category : Civil engineering
Languages : en
Pages : 122
Book Description
This edition takes into consideration the revisions of the Landfill Tax, Housing Grants Construction and Regeneration Act, and Contracts (Rights of Third Parties) Act. There are minor alterations to the contract that bring the wording into line with the Design and Construct Conditions of Contract. Other changes clarify the intention of the clause. In some sections the clauses have been re-numbered to present a more logical sequence to the contract. A few clauses have been changed substantially and an On Default performance Bond is included which has been drafted in more modern English.
Publisher: Thomas Telford
ISBN: 0727727893
Category : Civil engineering
Languages : en
Pages : 122
Book Description
This edition takes into consideration the revisions of the Landfill Tax, Housing Grants Construction and Regeneration Act, and Contracts (Rights of Third Parties) Act. There are minor alterations to the contract that bring the wording into line with the Design and Construct Conditions of Contract. Other changes clarify the intention of the clause. In some sections the clauses have been re-numbered to present a more logical sequence to the contract. A few clauses have been changed substantially and an On Default performance Bond is included which has been drafted in more modern English.
Ice Conditions of Contract
Author: Institution of Civil Engineers Staff
Publisher: Thomas Telford
ISBN: 0727703374
Category :
Languages : en
Pages : 94
Book Description
- Definitions and Interpretation - Engineers Representative - Assignment and Sub-Letting - Contract Documents - General obligations - Labour - Workmanship and Materials - Commencement Time and Delays - Liquidated Damages and Limitation of Damages for Delayed Completion - Completion Certificate - Maintenance and Defects - Alterations Additions and Omissions - Property in Materials and Plant - Measurement - Provisional and Prime Cost Sums and Nominated Sub-Contracts - Certificates and Payment - Remedies and Powers - Frustration - War Clause - Settlement of Disputes - Application to Scotland - Notices - Tax Matters - Metrication - Special Conditions
Publisher: Thomas Telford
ISBN: 0727703374
Category :
Languages : en
Pages : 94
Book Description
- Definitions and Interpretation - Engineers Representative - Assignment and Sub-Letting - Contract Documents - General obligations - Labour - Workmanship and Materials - Commencement Time and Delays - Liquidated Damages and Limitation of Damages for Delayed Completion - Completion Certificate - Maintenance and Defects - Alterations Additions and Omissions - Property in Materials and Plant - Measurement - Provisional and Prime Cost Sums and Nominated Sub-Contracts - Certificates and Payment - Remedies and Powers - Frustration - War Clause - Settlement of Disputes - Application to Scotland - Notices - Tax Matters - Metrication - Special Conditions
Ice Conditions of Contract Ground Investigation Version
Author: Institution of Civil Engineers (Great Britain)
Publisher: Thomas Telford
ISBN: 9780727732262
Category : Civil engineering contracts
Languages : en
Pages : 102
Book Description
- Acknowledgements - Contents of ICE Condition of Contract - Index to ICE Conditions of Contract - ICE Conditions of Contract Ground Investigation - Definitions and interpretation - Engineer and Engineer's representative - Assignment and sub-contrating - Contract documents - General obligations - Materials and workmanship - Commencement time and delays - Liquidated damages for delay - Certificate of substantial completion - Outstanding work and effects - Alterations, additions and omissions - Procedure for additional payment - Property in materials and contractor's equipment - Measurement - Provisional and prime cost sums and nominated sub-contrats - Certificates and payment - Remedies and powers - Avoidance and settlement of disputes - Application to Scotland and Northern Ireland - Notices - Tax matters - The construction (Design and Management) regulations 1994 - Special conditions - Form of tender - Appendix to form of tender - Form of agreement - ICE form of default bond - Contract price fluctuations
Publisher: Thomas Telford
ISBN: 9780727732262
Category : Civil engineering contracts
Languages : en
Pages : 102
Book Description
- Acknowledgements - Contents of ICE Condition of Contract - Index to ICE Conditions of Contract - ICE Conditions of Contract Ground Investigation - Definitions and interpretation - Engineer and Engineer's representative - Assignment and sub-contrating - Contract documents - General obligations - Materials and workmanship - Commencement time and delays - Liquidated damages for delay - Certificate of substantial completion - Outstanding work and effects - Alterations, additions and omissions - Procedure for additional payment - Property in materials and contractor's equipment - Measurement - Provisional and prime cost sums and nominated sub-contrats - Certificates and payment - Remedies and powers - Avoidance and settlement of disputes - Application to Scotland and Northern Ireland - Notices - Tax matters - The construction (Design and Management) regulations 1994 - Special conditions - Form of tender - Appendix to form of tender - Form of agreement - ICE form of default bond - Contract price fluctuations
ICE Conditions of Contract Ground Investigation Version 2nd Edition: Guidance Notes
Author: Institution of Civil Engineers Staff
Publisher: Thomas Telford
ISBN: 0727732560
Category : Building
Languages : en
Pages : 36
Book Description
- Introduction - Contract documents - Overall concept - Tendering procedure - Operation of the Contract - Notes on specific Clauses - Appendix 1. bond - Appendix 2. Contract Price Fluctuation
Publisher: Thomas Telford
ISBN: 0727732560
Category : Building
Languages : en
Pages : 36
Book Description
- Introduction - Contract documents - Overall concept - Tendering procedure - Operation of the Contract - Notes on specific Clauses - Appendix 1. bond - Appendix 2. Contract Price Fluctuation